Understand concurrent and pacing delays, how tribunals assess EOT under FIDIC & AACE standards, and how to prove entitlement with records.

Acceleration Claims in Construction: A Practical Guide for Engineers

Every delay begins with a moment. An approval not issued. A drawing not released. A delivery not made. The contract programme continues, but the works slip. In that instant, I face a choice: act with precision, or surrender entitlement. Delay Notices are not just paperwork. They are the legal mechanism that protects time, preserves claims, and prevents the imposition of liquidated damages. When handled casually, they collapse under scrutiny. However, when issued in compliance